The latest version of the <Beijing Family Home Decoration Decoration Construction Contract> (2003 Edition, revised in March 2004) BF-2003-0203 Beijing Family Room Decoration Project Construction Contract (2003 edition) Employer (Party A): Contractor (Party B): Contract No: Beijing Municipal Administration for Industry and Commerce Revised in March 2004 Instructions for use 1. The text of this contract applies to the family room decoration project in the administrative area of ​​this Municipality. This version of the contract text applies until the release of the new contract text. 2. The project contractor (Party B) shall have a business license issued by the administrative department for industry and commerce and a construction industry qualification certificate issued by the administrative department of construction. 3. Both parties A and B sign this contract directly, and the parties shall each hold one copy; where the contract is signed in each market of the city, it shall be in triplicate (Party A and Party B and the market organizer Each holds one.) 4. Commencement: After the completion of the preliminary work of the two parties through the design scheme, the first phase of the project funds, and the completion of the engineering technology, the commencement of operation of the materials and construction personnel to the construction site shall be deemed as commencement. 5. Completion: The project contents agreed in the contract (including indoor air quality inspection) are all completed, and acceptance by the contractor, supervision unit, and contractor will be considered as completion. 6. Acceptance of Acceptance: Contractors, supervision units, and contract-issuing parties shall be deemed to be qualified for inspection after they have signed and sealed the "Project Acceptance Receipt Form" or have not yet gone through the acceptance procedures but the enrollee has already used the equipment. 7. Extension of construction period: It means that the duration of the project will be extended accordingly if the project progress is not affected due to the responsibility of Party B. In case of delay of the construction period, Party B shall not be liable for breach of contract. Paste Stamp Duty Office Beijing Family Room Decoration Project Contract Agreement The Employer (hereinafter referred to as Party A): Attorney (Name): Ethnicity: Residence: ID number: Contact Phone: Mobile Number: Contractor (hereinafter referred to as Party B): Business License No: residence: Legal representative: Telephone: Attorney: Telephone: Building qualification certificate number: This project designer: Contact phone: Construction Team Leader: Contact Phone: In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and regulations, combined with the characteristics of decoration and decoration of family homes in this Municipality, Party A and Party B shall, on the basis of equality, voluntariness and consensus, contract with Party B to contract Party A's family room. The related matters of the decoration and decoration project (hereinafter referred to as the project) have reached the following agreement: The first project overview 1.1 Project location: 1.2 Project decoration area: 1.3 Project Type: 1.4 Project contents and practices (see quotation sheets and drawings); 1.5 Project contracting, take the following approach: (1) Party B works and packs all materials (see Attached Table 3). (2)Party B includes work and package materials, and Party A provides the rest of the materials (see Attached Tables 2 and 3). 1.6 Project Deadline (calculated on actual working days); Date of commencement of the year; Date of completion. 1. 7 Projects and Quotations (1) Project payment: The contract construction cost is (RMB) Amount of capital: (2) The quotation shall be based on the reference price of the Beijing home decoration project, and shall be agreed upon by both parties in accordance with the operating rules of the market economy and in accordance with the principle of higher prices and higher prices as an annex to this contract. (3) The quotations should be used together with the material quality standards and the preparation of the safety and security process as the basis for determining the project price. The second project supervision If this project implements project supervision, Party A shall sign the “project supervision contract†with the project supervision company approved by the construction administrative department, and notify Party B of the name, unit, contact information, and supervision engineer’s duties of the supervision engineer. . Article 3 Construction Drawings and Pre-evaluation Calculation of Indoor Environmental Pollution Control 3.1 The construction drawings are taken in the following way: (1) For Party A's own design, it is necessary to provide three copies of the construction drawings and pre-evaluation calculations for indoor environmental pollution control. Party A shall hold one copy and Party B shall hold two copies. (2) If Party A entrusts Party B to design, Party B shall provide three copies of the construction drawings and pre-evaluation calculations for indoor environmental pollution control. Party A shall hold one copy and Party B shall hold two copies. 3.2 The construction drawings and indoor environmental pollution control pre-evaluation calculation documents provided by both parties must meet the requirements of the "Guidelines for Indoor Environmental Pollution Control of Civil Building Projects" (GB50325-2001). 3.3 Both parties shall sign and confirm the construction drawings and the pre-evaluation calculations for indoor environmental pollution control. 3.4 Both parties shall not copy or transfer the construction drawings, design plans and other information provided by the other party to third parties without permission, nor shall they be used for projects other than this contract. Article 4 Party A's Work 4.1 Three days before the start of construction, conditions should be created for Party B's admission construction, so as not to affect the construction. 4.2 Water source, power supply and winter heating during construction period are provided free of charge. 4.3 Responsible for handling the start-up procedures of the property management department and the related expenses that should be paid by the owner. 4.4 Comply with the regulations of the property management department. 4.5 Responsible for coordinating the relationship between the construction personnel of Party B and the neighbors. 4.6 may not have the following behavior: (1) arbitrarily modify the main body and load-bearing structure. (2) Open the windows, doors or enlarge the size of the original doors and windows on the external walls, and remove the walls connecting the balconies and doors. (3) Paving more than one centimeter of stone in the interior, masonry wall, increase the floor load. (4) Destroy the kitchen and toilet floor waterproofing layer and demolition of hot, warm and gas pipelines. (5) Other actions that forced Party B to violate the regulations. 4.7 Where it is necessary to cover the contents listed in Section 4.6, Party A shall submit an application to the housing management department. The original design unit or a design unit with a corresponding qualification level shall examine and issue a written certificate for the safe use of the alteration plan, and then the housing Management approval. 4.8 During the construction period, Party A still needs to use the room partially, and Party A should be responsible for coordinating with Party B to do a good job of defense and fire fighting. 4.9 Participate in the supervision of the construction progress of the project quality, participate in the acceptance of engineering materials, inspection and acceptance of concealed projects, and completion acceptance. Article 5 Party B Work 5.1 Strictly implement the construction specifications, quality standards, safety operation regulations, fire prevention regulations, safety, quality assurance, and complete the project contents agreed in this contract on schedule. 5.2 Strict implementation of the construction site management regulations of the municipal construction administrative department: (1) Without the examination and approval procedures and reinforcement drawings of the housing management department, the construction main body and load-bearing structure in the project shall not be demolished, the ground load of the building shall not be added, and the original indoor heating, heating and gas pipeline facilities shall not be altered. (2) It shall not disturb people or pollute the environment. No decoration activities such as knocking, chiseling, planing, and drilling shall be conducted between 12:00 and 14:00, 18:00 and 8:00 of the next day. (3) Party B shall be liable for repairs and losses due to clogging, leakage, water stoppage, blackout, etc. caused by the decoration of the neighboring residential buildings. (4) Responsible for the protection of finished furniture, equipment, and furnishing of furnishings in the living room. (5) Ensure that the indoor and sewer pipes are open and the bathroom is clean. (6) To ensure the cleanliness of the construction site, clean up the construction site after daily completion. 5.3 Provide Party A with the conditions for inspecting various standards, specifications, calculations, reference prices, and other information involved in the signing and implementation of this contract by means of notifying the website and uniform publication. 5.4 If Party A is a minority nationality, Party B should respect its national customs and habits during the construction process. Article 6 Project Changes If there is any need to change the project contents agreed upon during the construction period, both parties shall agree on the agreement. The parties to the contract jointly sign a written change agreement and adjust the related engineering fees and duration. The engineering change agreement is used as the basis for the completion of the settlement and the extension of the construction period. Article 7 Material Supply 7.1 It shall be provided in accordance with the material supply methods and contents as stipulated in the “Detailed List of Engineering Materials and Equipment†of the contracted home decoration prepared by Party B. (1) Materials and equipment that should be provided by Party A. Party A shall notify Party B before materials and equipment arrive at the construction site. Both parties jointly accepted and handled the handover procedures for materials, equipment quality and environmental protection standards. (2) Materials and equipment provided by Party B, and Party B shall notify Party A before materials and equipment arrive at the construction site. The two parties jointly accepted the materials, equipment quality and environmental protection standards, and Party A confirmed the record. (3) The building decoration materials provided by both parties must comply with the “Minimum Standards for Indoor Decorations and Hazardous Substances†issued by the General Administration of Quality Supervision, Inspection and Quarantine, and have a test report issued by a professional inspection agency approved by the relevant administrative department. (4) If one party holds a reconsideration against the material provided by the other party, the inspection fee shall be paid in advance by the party. If the material fails to pass the inspection, the testing cost shall be borne by the other party. (5) After the materials and equipment provided by Party A are accepted and confirmed by Party B, the responsibility for the custody and quality control in construction use shall be borne by Party B. Article 8 Delays in duration 8.1 The delay in the date of completion due to the following reasons, confirmed by Party A, shall be postponed: (1) Changes in the amount of work or design changes; (2) Force majeure; (3) Party A agrees with the other circumstances of the extension of the construction period. 8.2 Due to the delay in the completion of the following reasons, the construction period shall be postponed: (1) Party A failed to complete the work it should be responsible for in accordance with the contract and affected the schedule; (2) If Party A fails to pay for the project according to the contract, it will affect normal construction; (3) Other circumstances that caused the delay of the construction period due to the responsibility of Party A. 8.3 If the responsibility of Party B cannot be completed on time, the construction period will not be postponed. The cost of rework due to Party B's cause of the quality of the project shall be borne by Party B. The construction period will not be postponed. 8.4 Judgment of delays caused by the duration of the work is based on the “word agreement recognized by both parties†as the basis for determining the responsibilities of both parties. Article 9 Quality Standard 9.1 The indoor environment pollution control of decoration shall be strictly followed in accordance with the standards of the "Guidelines for Indoor Environmental Pollution Control of Civil Building Projects" (GB50325-2001). 9.2 The construction quality of this project is implemented according to the following criteria: (1) "Quality Acceptance Criteria for Beijing Family Home Decoration Project" (DBJ/TO1-43-2003); (2) "Quality Acceptance Standard for Beijing Advanced Building Decoration Engineering" (DBJ/T01-27-2003). 9.3 When the two parties dispute the project quality and indoor air quality at the time of completion and acceptance, they shall apply for certification by a professional inspection institution approved by the relevant administrative department; the expenses related to the certification process shall be paid by the applicant and ultimately be borne by the responsible party. Article 10 Acceptance of the Project 10.1 Joint acceptance of project quality at the following stages during the construction process: (1) Material acceptance; (2) Hidden project acceptance; (3) Completion acceptance. 10.2 After the completion of the project, Party B shall notify Party A of acceptance and Party A shall organize acceptance within three days after receipt of the acceptance notice of completion. After passing the inspection and acceptance, the two parties shall complete the handover procedure, settle the balance, and sign the warranty. Party B shall submit to Party A the hydropower reform map of its construction part. 10.3 Before the completion of acceptance by the two parties, Party B shall be responsible for the protection of all the safety of the finished product and the site of the project. 10.4 The two parties have not gone through the check and acceptance procedures. Party A shall not be allowed to check in. If Party A's unauthorized check-in is deemed as satisfactory, the losses incurred shall be borne by Party A. 10.5 Completion Acceptance When the project quality, indoor air quality and economic aspects do not involve any major issues, the two parties may sign the “Agreement on the Existence and Acceptance of Completion and Acceptance Questions†(as an attachment to the completion acceptance form) after both parties negotiate in unanimous agreement. 10.6 Since the date of acceptance of the project by both parties, the warranty period for interior decoration works under normal conditions of use shall be two years, and the warranty period for leakage protection of kitchens and toilets with waterproof requirements shall be five years. Article 11 Payment Methods for Construction Funds 11.1 After the signing of the contract takes effect, Party A will pay the construction fee to Party B according to the contract in the contract: Payment Times Payment Time Construction Payment Ratio Payable Amount 50% of the first three days before the start of work More than half of the second project progress The third completion acceptance 5% 11.2 More than half of the progress of the project refers to the complete laying of water and electricity pipelines in the project. The completion of the wall and top base shall be completed in accordance with the process requirements. The basic safety and security of the doors, windows and fine wood products shall be the criteria for defining the half of the project. 11.3 After acceptance of the project, Party A shall review the project settlement statement submitted by Party B. If there is no objection within two days from the date of submission, Party A shall be deemed to have agreed to pay the balance of the project of Party B. 11.4 After the construction funds are fully settled, Party B issues a formal unified invoice to the project settlement certificate. Article 12 Liability for breach of contract 12.1 If one party fails to perform the contractual obligation to the other party in accordance with the contract, it shall bear the liability for compensation; if the party is punished for violating relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party. 12.2 If one of the parties is unable to continue to perform the contract, it shall promptly notify the other party and the responsible party shall bear the losses caused by the cancellation of the contract. 12.3 Party A did not pay the second or third construction payments according to the contractual deadlines without justified reasons. For each delay of one day, Party B shall pay Party B the liquidated damages for the delay of some construction costs. 12.4 As Party B's liability is delayed, the Party shall pay Party B the liquidated damages of 2% of the contractual engineering cost for each day of delay. 12.5 As Party B's responsibilities lead to unqualified project quality and indoor air quality, Party B shall carry out rework repair, comprehensive treatment and compensation according to the following agreement: (1) Party B must perform thorough rework to repair the site where the quality of the project is not qualified. Due to the rework, the delayed delivery of the project is regarded as the delay of the same project, and the liquidated damages shall be paid according to the standard of 12.4. (2) For unqualified indoor air quality, Party B must carry out comprehensive management. Delayed delivery of the project due to treatment is deemed as a delay in the same project, and the liquidated damages shall be paid according to the standard of 12.4. (3) If the indoor air quality is still not up to standard and is indeed the responsibility of Party B, Party B shall refund Party A the full price of the contracted project; Party A shall also be responsible for the non-compliance of the contract, and Party B may reduce the return ratio accordingly. Article 13 Dispute Resolution In case of disputes arising under this contract, both parties shall negotiate or apply to the market sponsoring unit, consumer associations, etc. for mediation, consultation, or mediation. If no settlement is reached, they shall sue in the people's court, or apply for arbitration in accordance with an arbitration clause or arbitration agreement otherwise reached. Article 14 Supplementary Provisions 14.1 This contract takes effect after both sides sign and seal the parties. 14.2 The project shall not be subcontracted after signing this contract. 14.3 Both parties may make changes or supplements to this contract in written form. However, if the party alters or supplements the responsibilities for reducing or exempting Party B from this contract, it shall still be subject to this contract. 14.4 The parties shall negotiate and settle the matter in accordance with the principle of fairness because the reasons for the inability to be responsible to the parties affect the performance of the contract or cause losses. 14.5 If Party B withdraws from the market, the market organizer shall first assume the liability for compensation; after the organizer assumes the responsibility, it shall have the right to seek compensation from Party B. 14.6 The contract is automatically terminated after it is completed. Article 15 Other Matters Party A (signature): Party B (seal): Legal representative: Attorney: Year Month Day Year Month Day Market organizer (seal): Legal representative: Attorney: contact number: year month day Schedule I Engineering quotation sequence No. Item Unit Price Quantity Total Amount Process Method, Material Description Party A's representative (signature and seal): Party B's representative (signed and sealed): Note: The amount of this form is more than the company can copy as an attachment to the contract. Schedule II Party A supplies engineering materials and equipment schedules sequence No. Material Name Unit Variety Specification Quantity Supply Time Supply Acceptance Location Party A's representative (signature and seal): Party B's representative (signed and sealed): Remarks: The supplied materials and equipment must have a test report provided by a professional inspection unit approved by the administrative department. Schedule III Party B supplies engineering materials and equipment schedules sequence No. Material Name Unit Variety Specification Quantity Supply Time Supply Acceptance Location Party A's representative (signature and seal): Party B's representative (signed and sealed): Remarks: The supplied materials and equipment must have a test report provided by a professional inspection unit approved by the administrative department. Schedule IV Project completion acceptance Acceptance time: year, month, day project name: construction place: Completion acceptance See Party A's signature (stamp): Supervision agency signature (seal): Party B's signature (seal): Remarks: In the completion acceptance, there are still issues that do not affect the overall project quality, and can be checked by both parties through agreement. However, an agreement on legacy issues after completion must be signed as the basis for resolving the remaining issues after arrival. Schedule 5 Home improvement project warranty Party A Party A's agent contact phone number Party B Legal representative telephone number Home improvement project address Commencement date Warranty period from year to month day Party A's representative (signature and seal): Party B's representative (signed and sealed): Remarks: 1. From the date of acceptance of completion, the warranty period for the calculation of the decoration and decoration shall be two years, and the warranty period for the leakage prevention of the kitchen and toilet with waterproof requirements shall be five years; 2. During the warranty period, due to the construction of Party B and the improper use of materials, the quality of the decoration and decoration problems must be maintained by Party B in a timely manner; 3. During the warranty period, due to Party A's use and improper maintenance, the finish is damaged or cannot be used normally. Party B shall repair the charges at its discretion; 4. This warranty is valid after both parties have signed and sealed it. Construction Contract Decoration Interior Decorating Home Decoration Decoration Design House Toilet Door Bathroom Door Bathroom Door Size Bathroom Size Bathroom Waterproof Price Overall Toilet Bathroom Design Toilet Waterproof Dsp Distributor,Best Dsp Distributor,Dsp Distributor For Sale,Sub Distributor Yantai Ciso Lubrication Technology Co.,LTD , https://www.cisolubrication.com